Z1DA--B170 Window Recaulking Services

What the notice says

SF 30 CONTINUATION SHEET AMENDMENT 0002 Solicitation No.: 36C25627Q0022 Project: B170 Courtyard Window Re Caulk CAVHS Purpose of Amendment The purpose of this amendment is to provide the Government s responses to vendor questions submitted prior to the deadline. The following Questions & Answers are hereby incorporated into the solicitation. These clarifications do not change the scope of work unless explicitly stated. Only the Contracting Officer may authorize changes per FAR 52.212 4(c). SECTION: QUESTIONS & ANSWERS General Administrative Items Q1. Will the Government confirm that offers should be submitted via email to andrew.misfeldt@va.gov? A1. Yes. Submit one consolidated PDF ( 10MB), font Arial 11, in accordance with the solicitation instructions. Q2. Are there page limitations? A2. No page limits apply. The file-size limit of 10MB governs. Q3. Which form must be submitted SF 1449 or SF 1442? A3. Offerors shall submit a signed SF 1449. SF 1442 is not required. Evaluation Factors Q4. Please confirm the evaluation factors. A4. Evaluation consists of: Factor I Approach & Quality Management Factor II Professional Qualifications & Specialized Experience Factor III Past Performance Factor IV Price Factors I III are equal in importance and collectively approximately equal to Price. Q5. Does managing one subcontractor satisfy Past Performance requirements? A5. Yes, provided the offeror served as the prime contractor. Site Visit, Access, & Logistics Q6. Will there be a site visit? A6. A site visit was held on October 14, 2026. No additional site visits will be conducted. Q7. Please confirm logistical restrictions. A7. Approximate curtainwall height is 50 ft (verify independently). Elevator weight limit is 4,000 lbs. Courtyard door widths are 36 58 . Quiet hours are 2 3 PM and 10 PM 5 AM. Coordinate courtyard occupation with nursing staff. Q8. Are badges required? A8. Not for courtyard work during business hours. Badges are required for roof access. Delays caused by incomplete contractor submissions are not excusable delays. Scope Clarifications Q9. Does work occur along the entire curtainwall or only at leak locations? A9. Work shall occur along the entire curtainwall interface within Courtyards 1B and 1C to provide a continuous and complete seal. Q10. Should the entire length be repaired for a uniform seal? A10. Yes. Q11. Are cover caps replaced everywhere? A11. No. Replace only caps that are missing or cannot be reattached. Q12. Are other courtyard walls included? A12. No. Only the curtainwall/TPO/wall interface is included unless otherwise directed by the CO. Q13. Will the Government provide as builts or record drawings? A13. No. They are not available. Q14. Will the Government provide quantities? A14. No. Offerors must determine all quantities during the site visit. These measurements are binding for proposal purposes. Q15. Is full perimeter window caulking included? A15. No. Only the interfaces described in the SOW apply. Q16. Clarify termination bar installation. A16. Install the bar above the cant strip to secure the existing TPO using fasteners compatible with the substrate. Q17. Clarify face cap/flashing quantities. A17. Approximately 14 vertical caps have slid; one horizontal cap is missing; two require replacement. Remove flashing attached to the ground level base face cap. Offerors must verify all quantities. Q18. Will the awning require removal? A18. Not anticipated. Do not include awning removal unless CO directed. Q19. How many pavers must be moved and how should they be stored? A19. Approximately 70 pavers must be moved. Store in the courtyard, stacking no more than six high. Specifications, Submittals, & Warranty Q20. Which parts of VA 07 54 23 apply? A20. Membrane accessory materials and compatibility requirements apply. VA 07 92 00 applies to sealant products. Where requirements conflict, the more stringent governs. Q21. Confirm applicability of installer approvals, warranty, submittals, and pre installation m…